Klein Legal

Klein Legal Klein Legal is a Sunshine Coast based law firm and are experts in litigation and dispute solutions.

Commercial Litigation, Building and Construction Law, Wills and Estate Disputes, Debt Recovery, Property Disputes and Insolvency.

WE'RE HIRING!!Are you a litigation lawyer who values flexibility, genuine support, interesting work, and down to earth l...
07/05/2026

WE'RE HIRING!!

Are you a litigation lawyer who values flexibility, genuine support, interesting work, and down to earth leadership with an amazing team? Come work with us!

We are looking for a litigation lawyer (3yr+PAE) who has strong attention to detail, builds strong relationships with clients and colleagues, can work automosly, and has a desire to work remotely.

Contact us today at [email protected].

We value high-quality people and renumerate generously when we find them.

We can't wait to hear from you! 🥳

You're invited to our Worplace Health & Safety Seminar by Simon Grant, Barrister-at-law.Are you across your workplace he...
04/04/2026

You're invited to our Worplace Health & Safety Seminar by Simon Grant, Barrister-at-law.

Are you across your workplace health and safety obligations?

Under the Work Health and Safety law we are required to assess risks and implement and review control measures in your business to prevent or minimise exposure to these risks. In Queensland, breaches of duties are owed under these laws are categorised as criminal offences. Penalties for workplace health and safety offences are generally fines; however, the most serious offences can lead to imprisonment.

If you want to properly understand these laws to make sure you are compliant, you’re invited to join us for a FREE presentation by Simon Grant, Barrister-at-law as he shares his extensive knowledge and experience in this area of law.

The details are:

When: 1:00pm, 16 April 2026

Where: Via zoom or in person at Level 19, 200 Mary Street, Brisbane, Qld

RSVP by 10 April 2026

Spaces are limited - so make sure you register your interest today!

Register via the link in our bio.

https://www.eventbrite.com.au/e/workplace-health-and-safety-seminar-by-simon-grant-barrister-at-law-tickets-1986699988145?aff=ctntntshareoninstagram

Watch this space... 👀 Anticipation is exciting, right?!
09/03/2026

Watch this space... 👀

Anticipation is exciting, right?!

We have been working hard over the past couple of years at building the right team of people with the right skill set to...
08/03/2026

We have been working hard over the past couple of years at building the right team of people with the right skill set to bring you the best possible service, and we have definitely got the formula right. ✔️

If you're looking for solicitors who advocate only in your best interests & who have your back, you have found the right team for you.

The goal is simple. Protect your legal position and help you move forward with clarity and confidence.Most building disp...
23/02/2026

The goal is simple. Protect your legal position and help you move forward with clarity and confidence.

Most building disputes start the same way. Something shifts on site, communication breaks down, and suddenly, you are exposed to costs, delays & blame.

We provide clear advice, practical strategy, and a structured process to protect your position, reduce risk, and help you move forward with confidence.

Get started today!

She'll be right... or will she? Do your future self a favour & know what you're getting yourself into before you sign th...
15/02/2026

She'll be right... or will she?

Do your future self a favour & know what you're getting yourself into before you sign that contract or engage those services or go into business with that person.

It is always better to go into things with your eyes wide open than to regret it later. Know what it means for you from a legal perspective. What happens if things go south? What will that look like for you? Does your contract deal with it?

Get legal advice upfront & be prepared. Your future self will thank you later.

#

12/02/2026

Did you know about section 42 of the QBCC Act?

You do now.

Make sure you turn your mind to this section of the QBCC Act if you're looking to carry out or engage someone to carry out building work in QLD.

09/02/2026

Lawyers you can trust.

29/01/2026

This recent domestic building dispute application before the QCAT between a homeowner and a builder demonstrates the importance of proper contract administration.

In Osborn v Buildrite (Qld) Pty Ltd [2025] QCAT 552, the QCAT was required to make a decision about three (3) very common issues that arise in domestic building disputes:

The impact of variations that were not documented;

whether writing ‘NA’ next to the ‘liquidated damages’ clause meant the homeowner was excluded from claiming liquidated damages altogether; and

what impact no extension of time requests have on claiming delay caused by the homeowner.

Variations


In this case, the contract plans provided that the builder was required to construct raked ceilings. The builder argued that the parties had varied the work to change the ceiling. However, there was no documented evidence of this. The Tribunal awarded damages to the homeowner for the cost of removing the ceiling and building it as per the contract plans.

Liquidated Damages – ‘NA’

The homeowner claimed damages for late completion of the build by the builder. The builder relied on there being no ‘liquidated damages’ by reason of writing ‘NA’ next to the relevant clause of the contract. The Tribunal rejected the argument that no damages could be claimed by the homeowner for late completion where the parties had written ‘NA’ next to the liquidated damages clause under the contract.

EOT’s

The Builder claimed that the homeowner caused / contributed to the delay in completion of the build. The Tribunal found that there was a mechanism for dealing with the extension of time claims under the contract, which was not followed, and therefore, time was not extended under the contract.

The above is a short summary of issues we regularly see occurring in disputes between homeowners and builders and highlights the importance of understanding your contract as well as administrating them properly.

If you need legal advice about how to properly administer your contracts to avoid these types of disputes or if you are involved in a legal dispute that you need help resolving, contact us today!

12/01/2026

Between a busy lead up to Christmas and what seemed like an even more busy Christmas shutdown period, we're back at it and ready to assist you with your legal matter today!

If you're looking to start 2026 on a positive note by resolving your legal dispute, contact us today.

As we draw close to the end of 2025, I just wanted to say a huge thank you to all of our clients, referrers, friends, an...
17/12/2025

As we draw close to the end of 2025, I just wanted to say a huge thank you to all of our clients, referrers, friends, and family for making 2025 our best year!

Through the continued support of those around us, we were able to grow & expand our business this year to reach new heights & service more clients.

Thank you to our amazing team as well. I believe that surrounding yourself with the right people is the pillar to great success in life & business.

I can't wait to see what 2026 has in store!! ♡

Address

6c/9 Capital Place
Birtinya, QLD
4575

Opening Hours

Monday 8:30am - 5pm
Tuesday 8:30am - 5pm
Wednesday 8:30am - 5pm
Thursday 8:30am - 5pm
Friday 8:30am - 5pm

Website

Alerts

Be the first to know and let us send you an email when Klein Legal posts news and promotions. Your email address will not be used for any other purpose, and you can unsubscribe at any time.

Contact The Business

Send a message to Klein Legal:

Shortcuts

Share

Category